Description
C-550, Notice to Proceed fixes the date when the contract time starts to run and when the contractor may start to perform. The new 2018 edition Includes a new provision for liquidated damages.
C-550 2018 Notice to Proceed
$74.00
ABOUT EJCDC
The Engineers Joint Contract Documents Committee (EJCDC) is a joint venture of three major organizations of professional engineers. Since 1975, EJCDC has developed and updated fair and objective standard documents that represent the latest and best thinking in contractual relations between all parties involved in engineering design and construction projects.
Recent Posts
- Insurance company’s duty to defend and indemnify contractor against owner’s breach of contract claim. Crum & Forster Specialty Insurance Co. v. GHD Inc. United States Court of Appeals for the Seventh Circuit (2019), by Hugh Anderson
- Interpretation of ambiguous drywall finishing specifications. Appeal of KiewitPhelps. Armed Services Board of Contract Appeals (2019), by Hugh Anderson
- Contractor’s contractual indemnification obligation to project’s architect/engineer. Valdez v. Turner Construction Co. Appellate Division of the Supreme Court of New York (2019), by Hugh Anderson
- Engineering firm’s exposure to liability to low bidder that did not receive the award of contract. John Rocchio Corp. v. Pare Engineering. Supreme Court of Rhode Island (2019), by Hugh Anderson
- Application of the statute of repose to breach of contract claims. New Riegel Local School District Board of Education v. The Buehrer Group Architecture & Engineering, Inc. Supreme Court of Ohio (2019). by Hugh Anderson